1991/02/12 City Council Resolution (6)RESOLUTION NO. 91 -27
RESOLUTION CALLING FOR CONSTRUCTION BIDS
MILLBRAE AVENUE ASSESSMENT DISTRICT, PROJECT NO. 1988 -1
The City Council of the City of Rohnert Park resolves:
1. This City Council has given preliminary approval to the
report of the Engineer of Work for improvements in Millbrae Avenue
Assessment District, Project No. 1988 -1, City of Rohnert Park,
Sonoma County, California. The report includes plans and
specifications for the construction of improvements described in
the report.
2. The City of Rohnert Park will receive sealed proposals
for this construction not later than 2:00 P.M. on Tuesday, March
12, 1991, in the office of the City Clerk located at City Hall,
6750 Commerce Boulevard, Rohnert Park, CA 94928. At that time and
place the sealed proposals will be publicly opened, examined and
declared.
3. The Council reserves the power in its discretion to
reject all proposals. The award of construction contract, if made,
shall be made to the lowest responsible bidder within the time
fixed in the specifications (or any extension of time agreed to by
the Engineer of Work and the lowest responsible bidder). -
4. The City Clerk is directed to publish a notice inviting
sealed proposals in the ROHNERT PARK- COTATI CLARION in accordance
with the Municipal Improvement Act of 1913. The Engineer of Work
is authorized to give additional notice and to distribute
additional information as necessary in the judgment of the Engineer
of Work, to secure competitive bidding.
5. The City Council hereby determines that in the event
the contractor does not complete the work within the time specified
in the proposed contract or within such further time as this
Council shall have authorized, the contractor shall pay to the City
liquidated damages in the amount of $100.00 per day for each and
every calendar day's delay in finishing the work beyond the
completion date specified in said contract. Additional provisions
with regard to said time of completion and liquidated damages are
set forth in the specifications, which provisions are hereby
referred to and incorporated herein by reference.
I HEREBY CERTIFY that the foregoing is a full, true and
correct copy of a resolution duly passed and adopted by the City
Council of the City of Rohnert Park, Sonoma County, California, at
a meeting thereof, held on the 12th day of February, 1991, by the
following vote of the members thereof:
AYES: ( 5 ) Councilmembers Hol 1 i ngsworth, Hopkins, Reilly, Spiro and Eck
NOES: (0) Councilmembers
ABSENT: (0) Councilmembers
ABSTAIN: (0)Councilmembers
APPROVED:
Mayor
2