Loading...
2017/11/14 City Council Resolution 2017-129RESOLUTION NO. 2017-129 A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF ROHNERT PARK AUTHORIZING AND APPROVING A PUBLIC IMPROVEMENT AGREEMENT FOR THE VAST OAK EAST IN -TRACT, BACKBONE, AND HINEBAUGH CREEK TRAIL PHASE TWO LANDSCAPING IMPROVEMENTS WITH THE UNIVERSITY DISTRICT LLC AND VAST OAK LP AND RELATED ACTIONS WHEREAS, on May 23, 2006, the City Council of the City of Rohnert adopted Resolution No 2006-141 approving the Final Environmental Impact Report (EIR) for the University District Specific Plan Area including a draft EIR, a recirculated draft EIR, response to comments, changes, clarifications, and corrections to the draft EIR and recirculated draft EIR and appendices (together the "2006 EIR"); and WHEREAS, on April 8, 2014, the City Council of the City of Rohnert Park adopted Resolution No. 2014-032 approving an addendum to the 2006 EIR (together with the 2006 EIR collectively called the "Updated Final EIR"); and WHEREAS, on April 8, 2014, the City Council of the City of Rohnert Park adopted Resolution 2014-035 approving the Tentative Map for the University District Plan, prepared by MacKay & Somps and dated February 2014 (the "Tentative Map"), subject to certain conditions of approval ("Conditions"); and WHEREAS, on April 22, 2014, the City Council of the City of Rohnert Park adopted Ordinance No. 878, approving a Development Agreement ("Development Agreement") between the City of Rohnert Park and Vast Oak Property L.P. and University District LLC ("Developer"); and WHEREAS, the Developer intends to file the Final Maps for Phases 2-A, 2-13, 2-C, and 2-D for the Vast Oal< East Property; consisting of 323 single-family residential lots; and WHEREAS, the Development Agreement and the Conditions of Approval include requirements for Developer to construct the following improvements in conjunction with the first Final Map filed for the University District Property: all in -tract improvements within the Final Map areas, including streets, storm drainage, water, sewer, recycled water, joint trench and streetlighting, landscaping, and the Hinebaugh Creek Trail Phase Two; and WHEREAS, the Developer has previously entered into Improvement Agreements for the construction of in -tract and backbone utilities, joint trench and streetlighting, and street surface improvements, which constitute a portion of the required improvements; and WHEREAS, the Developer has submitted plans and specifications for the improvement of the In -Tract, Backbone, and Hinebaugh Creek Trail Phase Two Landscaping ("Improvement Plans") which have been reviewed by the City Engineer and determined to be technically accurate and in conformance with the Conditions of Approval, and which collectively include all required improvements not included in prior improvement agreements; and WHEREAS, the Developer has posted performance and labor and materials bonds in conjunction with the Improvement Agreements for the construction of in -tract and backbone street surface improvements, joint trench and landscaping, and which include the cost of landscaping in the following amounts: 1) Kingwood Road and Knight Road Backbone Landscaping Improvements: Seventy Three Thousand, Eight Hundred Dollars and No Cents ($73,800.00). 2) Phase 2-13, 2-C, and 2-D and Hinebaugh Creek Trail Phase Two Landscaping Improvements: Four Hundred Thirty Thousand, Three Hundred Forty Dollars and No Cents ($430,340.00). WHEREAS, the City and Developer desire to enter into a Public Improvement Agreement for the In -Tract, Backbone and Hinebaugh Creek Trail Landscaping to more thoroughly define the terms and conditions of the construction and dedication obligations under the conditions of approval. NOW, THEREFORE, BE IT RESOLVED by the City Council of the City of Rohnert Park that it does hereby authorize and approve the Public Improvement Agreement for the In - Tract, Backbone and Hinebaugh Creek Trail Phase Two Landscaping with the University District LLC and Vast Oak LP included as Exhibit A to this Resolution. BE IT FUTHER RESOLVED that based on the evidence presented at the duly noticed public meeting of November 14, 2017, the City Council of the City of Rohnert Park finds that the public improvements and activities were adequately described and mitigated in the University District Specific Plan Area Updated Final EIR, and that no other CEQA analysis is warranted. BE IT FURTHER RESOLVED that the City Manager is hereby authorized and directed to execute the Public Improvement Agreement for the Vast Oak East In -Tract, Backbone, and Hinebaugh Creek Trail Phase Two Landscaping with University District LLC in substantially similar form to the agreement attached hereto and incorporated by this reference as Exhibit A subject to minor modification by the City Manager or City Attorney. DULY AND REGULARLY ADOPTED this 14th day of November, 2017. CITY OF ROHNERT PARK Jake Me kenzie, Major ATTEST: a 0- a L=_�� JoAnne M. Buergler, Cit Clerk Attachment: Exhibit A Q AHANOTU: BELFORTE: CALLINAN: STAFFORD: A� C MACKENZIE:� AYES: (� ) NOES: ( le) ) ABSENT: ( C) ) ABSTAIN: ( o ) (2) 2017-129 Exhibit A to Resolution RECORDING REQUESTED BY ) AND WHEN RECORDED MAIL To. ) ) City of Rohnert Park ) 130 Avram Avenue ) Rohnert Park, California 94928-2486 ) Attention: City Clerk ) (Space Above This Laze for Recorder's Use Only) Exempt from recording fee per Gov. Code § 27383. PUBLIC IMPROVEMENT AGREEMENT BY AND BETWEEN THE CITY OF ROHNERT PARK AND UNIVERSITY DISTRICT LLC AND VAST OAK LP FOR THE VAST OAK EAST IN - TRACT, BACKBONE, AND HINEBAUGH CREEK TRAIL PHASE TWO LANDSCAPING This Public Improvement Agreement (the "Agreement") is made and entered into on this day of 2017 (the "Effective Date") by and between University District, LLC, a Delaware Limited Liability Company, Vast Oak LP , a California Limited Partnership ( together "Developer"), and the CITY OF ROHNERT PARK, a California municipal corporation ("City"). City and Developer are sometimes referred to hereinafter individually as "Party" and collectively as "Parties". RECITALS A. On April 8, 2014, the City Council of the City of Rohnert Park adopted Resolution No. 2014-035, approving the Tentative Map for the University District Vast Oak Property, prepared by MacKay & Somps and dated February 2014 (the "Tentative Map"), subject to certain conditions of approval (the "Conditions"). B. On April 22, 2014, the City Council of the City of Rohnert Park adopted its Ordinance No. 878 approving a Development Agreement with the Developer (the "Development Agreement") C. Both the Conditions and the Development Agreement require that the Developer provide adequate in -tract infrastructure for its development. D. The Developer has submitted plans, specifications and drawings for the various in -tract landscape improvements (the "Improvements"). The plans for the Improvements are listed in the summary below (the "Improvement Plans"). These plans are on file in the office of the City Engineer and have been approved as outlined below. • Landscape Construction Documents for: Kingwood Road and Knight Road Backbone Landscape, Vast Oak at University District, Rohnert Park, CA, 2017, prepared by vanderToolen and Associates, 15 Sheets (Sheets L-0 thru L-14), and approved by the City Engineer on 12017. Landscape Construction Documents for: Cypress East at University District Production, Parkways, Vast Oak at University District, Rohnerl Park, CA, 2017, prepared by vanderToolen and Associates, 8 Sheets (Sheets L-0 thru L-7), and approved by the City Engineer on , 2017. (Phase 2-13) Landscape Construction Documents for: Sycamore at University District Parkways, Production, Phase One, Vast Oak at University District, Rohnert Park, CA, 2017, prepared by vanderToolen and Associates, 12 Sheets (Sheets L-0 thru L-11), and approved by the City Engineer on , 2017. (Phase 2-C) Landscape Construction Documents for: Chestnut at University District, Vast Oak at University District, Rohnert Park, CA, 2017, prepared by vanderToolen and Associates, 8 Sheets (Sheets L-0 thru L-7), and approved by the City Engineer on , 2017. (Phase 2-D) Landscape Construction Documents for: Hinebaugh Creek Trail, Phase Two, Vast Oak at University District, Rohnert Park, CA, , 2017, prepared by vanderToolen and Associates, 19 Sheets (Sheets L-0 thru L-19), and approved by the City Engineer on , 2017. E. Developer intends to file final maps for Phases 2-A, 2-B, 2-C, and 2-D within the University District Vast Oak Property, consisting of 323 single-family residential lots (the "Project") and wishes to begin the construction of the landscaping improvements and may complete the work in phases. F. City and Developer desire to enter an agreement providing for the construction and installation of the Improvements in accordance with the plans, specification and drawings described in Recital D. AGREEMENT NOW, THEREFORE, in consideration of the faithful performance of the terms and conditions set forth in this Agreement, the parties hereto agree as follows: I. Incorporation of Recitals. The foregoing Recitals are true and correct and, together with the Project Approvals and the requirements of Chapter 16.16 of the RPMC, are hereby incorporated into and form a material part of this Agreement Purpose and Effective Date 2.1 Purpose. The purpose of this Agreement is to guarantee completion of the Improvements and ensure satisfactory performance by Developer of Developer's obligations to satisfy the Conditions for the Project. 2.2 Effective Date. The Effective Date of this Agreement shall be as set forth above. 3. Property Subject to Agreement. The property which is the subject of this Agreement is located in the City of Rohnert Park, Sonoma County, California, and is described in Exhibit A, attached hereto (the "Property"). 4. Improvements 4.1 Duty to Install Improvements. Developer will design, construct, install and complete, or cause to be constructed, installed and completed, at the Developer's sole cost and expense, the Improvements, in accordance with the Improvement Plans (defined in Recital D above) and to the satisfaction of the City Engineer, in his/ her reasonable discretion. Developer will also supply all labor and materials therefor, all in strict accordance with the terms and conditions of this Agreement. The 2 construction, installation and completion of the Improvements including all labor and materials furnished in connection therewith are hereinafter referred to collectively as the "Work." City shall not be responsible or liable for the maintenance or care of the Improvements until City formally approves and accepts them in accordance with its policies and procedures. City shall exercise no control over the Improvements until approved and accepted. Any use by any person of the Improvements, or any portion thereof, shall be at the sole and exclusive risk of the Developer at all tunes prior to City's acceptance of the Improvements. Developer shall maintain alt the Improvements in a state of good repair until they are completed by Developer and approved and accepted by City. Maintenance shall include, but shall not be limited to, repair of pavement, curbs, gutters, sidewalks, signals, parkways, water mains, and sewers; maintaining all landscaping in a vigorous and thriving condition reasonably acceptable to City; removal of debris from sewers and storm drains; and sweeping, repairing, and maintaining in good and safe condition all streets and street improvements. It shall be Developer's responsibility to initiate all maintenance work, but if it shall fail to do so, it shall promptly perform such maintenance work when notified to do so by City. If Developer fails to properly prosecute its maintenance obligation under this section, City may do all work necessary for such maintenance and the cost thereof shall be the responsibility of Developer and its surety under this Agreement. Prior to undertaking said maintenance work, City agrees to notify Developer in writing of the deficiencies and the actions required to be taken by the Developer to cure the deficiencies. Developer shall have thirty (30) days from the date of the notice within which to correct, remedy or cure the deficiency. If the written notification states that the problem is urgent and relates to the public health and safety, then the Developer shall have twenty-four (24) hours to correct, remedy or cure the deficiency. City shall not be responsible or liable for any damages or injury of any nature in any way related to or caused by the Improvements or their condition prior to acceptance. 4.2. Completion Date. Developer will complete the Work within two years of the Effective Date or as required by the Conditions of Approval for the University District Vast Oak Property, whichever is sooner. All Work will be completed in a good and workmanlike manner in accordance with accepted design and construction practices. This completion date may be extended by the City in its sole and absolute discretion at the request of Developer, which request shall be accompanied by a written assurance acceptable to the City Attorney that the securities required by Section 5 shall remain enforceable throughout the terra of the extension. 4.3. Estimated Cost of Work. The estimated cost of the Work is as follows: a) Kingwood Road and Knight Road Backbone Landscape Improvements: Seventy Three Thousand, Eight Hundred Dollars and Zero Cents ($73,800) b) Phase 2-13, 2-C, and 2-D and Hinebaugh Creek Trail Phase Two Landscape Improvements: Four Hundred Thirty Thousand, Three Hundred Forty Dollars and Zero Cents ($430,340.00) Notwithstanding this estimate, Developer hereby acknowledges and agrees that (a) the actual costs to complete the Work may significantly exceed this estimate, (b) this estimate in no way limits Developer's financial obligation, and (c) that Developer is obligated to complete the Work at its own cost, expense, and liability. 4.4. Modifications to the Plans. Approval of this Agreement by City does not release Developer of its responsibility to correct mistakes, errors or omissions in the Improvement Plans. If, at any time, in the opinion of the City Engineer, in his/her reasonable discretion, the Improvement Plans are deemed inadequate in any respect Developer agrees to make such modifications, changes or revisions as 91 necessary in order to complete the Work in a good and workmanlike manner in accordance with accepted design and construction standards. 4.5. Foreman or Superintendent. Developer shall give personal attention to the Work. A competent foreman or superintendent, satisfactory to the City Engineer, in his/her reasonable discretion, with authority to act for and on behalf of Developer, shall be named in writing by Developer prior to commencement of the Work, shall be present on the Property during the performance of the Work. Any change in the superintendent will require advance notification to the City Engineer and concurrence of the City Engineer and the Engineer of Record for the Improvement Plans. 4.6. Encroachment Permits. Developer shall obtain, at its sole cost and expense, any encroachment permits required by the City in order to perform the Work. 4.7. Inspection: All of the Improvements shall be constructed and installed to the satisfaction of the City Engineer, in his or her reasonable discretion. City and its authorized agents shall, at all times during the construction of the Improvements, have free access to the Improvements and shall be allowed to examine and inspect the Improvements and all material used and to be used in the Improvements to confirm compliance with City Plans and Specifications. 4.8. Commencement of Construction and InsWetion. Developer and its contractor or subcontractors shall not commence construction of the Improvements until Developer has received written authorization from City to proceed. Written authorization shall be in the form of signed approved plans along with permit issuance, including any encroachment permit required to carry on construction activities in the City's right-of-way as described in Section 4.6. All work performed on the Improvements shall be done in strict compliance with the City approved plans, specifications and the contract documents and in a good and workmanlike manner. All work performed by Developer, its contractor or agents to construct the Improvements shall be subject to inspection by City. All fees and costs to construct the Improvements shall be borne solely by Developer (including the applicable Inspection Fee in accordance with the City's adopted Engineering Fee Schedule). Inspection by City or its employees or agents shall not relieve Developer of its liability for design defects or improper or inadequate workmanship. 4.9. City's Inspection. Administration and Testing Costs. Developer shall pay to City the actual cost for all inspection, administration and testing services furnished by City in connection with this Agreement, including those performed by consultants under contract with the City (the "City Costs"). City agrees not to double charge Developer (through the imposition of both a processing fee and a consultant charge) for any individual monitoring, inspection, testing or evaluation service. In addition, City agrees to limit its use of outside consultants to those reasonably necessary or desirable, as determined by the City Manager or his designee in his reasonable discretion, to accomplish the requisite inspection, administration and monitoring. The estimated cost for the inspection, administration and testing services is Seven Thousand, Five Hundred Sixty Two Dollars and Ten Cents ($7,562.10) (the "Estimated Cost"). Concurrently with the execution of this Agreement, Developer shall deposit an amount equal to the Estimated Cost with City for the payment of the City Costs. In the event that the Estimated Cost is insufficient to cover the actual City Costs incurred, Developer shall, upon notice in writing by the City Engineer, deposit such additional amount as may be required to pay the City Costs. Any amount of the Estimated Cost, initial deposit or additional amounts deposited remaining after payment of all City Costs will be returned to Developer. City may, at its discretion, deposit such funds in an interest-bearing account and retain any and all interest earned. 4.10. No Waiver by City. Inspecting of the work and/or materials, or approval of work and/or materials, or a statement by an officer, agent or employee of the City indicating the work complies m with this Agreement, or acceptance of all or any portion of the work and/or materials, or payments thereof, or any combination of all of these acts shall not relieve Developer or its obligation to fulfill this Agreement; nor is the City by these acts prohibited from bringing an action for damages arising from the failure to comply with this Agreement. 4.11. Erosion Control. Pursuant to Rolinert Park Municipal Code Chapter 15.52, Developer shall be responsible for the control of erosion on the Property and shall prevent its entry into the storm drainage system. 4.12. Prevailing Wages. The work of the Improvements do not constitute a "public work" as defined in the California Labor Code, section 1771, et seq ("Labor Code Regulations") because the work is not being paid for in whole or in part out of public funds. City and Developer acknowledge that the construction of the Improvements is not subject to the payment of prevailing wages. Further, Developer agrees to defend, indemnify and hold City, its elected officials, officers, employees, and agents free and harmless from any and all claims, damages, suits or actions arising out of or incident to Developer's obligations under this section and the payment of prevailing wages. 4.13. Contractor Licenses. All work performed on the Improvements shall be done only by contractors licensed in the State of California and qualified to perform the type of work required and comply with the City's Business License Ordinance. 4.14. Repair of Work Damaged During_ Construction. Developer agrees to repair or have repaired in a timely manner at its sole cost and expense all public roads, streets, or other public or private property damaged as a result of or incidental to the Work or in connection with the development of the Property or to pay to the property owner of any damaged road, street or property the full cost of such repair. In addition, Developer shall obtain the written acceptance of such repair or payment from any owner whose private property was repaired by Developer or to whom Developer has paid the full cost of such repair in accordance with this Section 4.14. City shall be under no obligation whatsoever to accept the Work completed under this Agreement until such time as all repairs have been completed or have been paid for and written acceptances have been provided to the City Engineer, except as otherwise provided in section 5.18.1 4.15. Payments. Developer agrees that it will pay, when due, all those furnishing labor or materials in connection with the Work. Developer further agrees that pursuant to Government Code section 66499.7, the Labor and Materials Bond provided by Developer in accordance with Section 5.1.2 of this Agreement shall not be released if any mechanics liens or stop notices are outstanding, unless said liens are released by bond in compliance with Civil Code section 3143. 4.16. Liability for Work Prior to Formal Acceptance. Until the City Council has formally accepted the Improvements, Developer shall be solely responsible for all damage to the work, regardless of cause, and for all damages or injuries to any person or property at the work site, except damage or injury due to the sole negligence of City, or its employees. Developer shall replace or repair any portion of the Improvements that have been destroyed or damaged prior to final acceptance of completed work by the City Council or the City Engineer. Any such repair or replacement shall be to the satisfaction and subject to the approval of the City Engineer. Developer shall repair to the satisfaction of the City Engineer any damage to the utilities systems, concrete work, street paving or other public improvements that may occur in connection with the Improvements work. 5 4.17. Completion of Work. After Developer (a) completes the Work in accordance with the Improvement Plans and the terms and conditions of this Agreement, (b) repairs any road, street, or private or public property damaged as a result of the Work or pays the full cost of such repair to the owner whose property was damaged and (c) obtains the written acceptance of such repair or payment from any owner whose private property was repaired by Developer or to whom Developer paid the fill cost of such repair, Developer will provide City with a written notice of completion, together with copies of all written acceptances. 4.18. f=inal Acceptance. 4.18.1 Notice o'f Completion. Within thirty (30) days of receipt of Developer's written notification pursuant to Section 417 above, City Engineer shall inspect the Work and repairs and review the written acceptances, if any, and send Developer a written notice stating whether the Work and repair are complete to the satisfaction of the City Engineer, in his/her reasonable discretion, and whether the written acceptances have been provided. If the Work and repair are, in the opinion of the City Engineer, not complete and satisfactory, and/or written acceptances have not been provided, the City Engineer will list the deficiencies that must be corrected to find the Work and repair complete and satisfactory. Upon satisfactory completion of the Work and repair and submittal of written acceptances, the City Engineer will send Developer a written notice of satisfactory completion. The requirement to]- written orwritten acceptances may be waived by the City Engineer, in his/her reasonable discretion, if Developer has made commercially reasonable efforts to obtain such acceptances. City Engineer's failure to respond to Developer's written notification within thirty (30) days will not be deemed a breach or default under this Agreement. 4.18.2 Acce Lance of Improvements. After sending Developer a written notice of satisfactory completion pursuant to Section 4.18.1, the City Engineer will recommend acceptance of the Improvements, or a portion thereof, to the City Council. In conjunction with such recommendation, the City Engineer will recommend the acceptance of the offers of dedication shown on the final map for the Property. The acceptance of the Improvements, offers of dedication and right-of-way and easements, if any, shall be by resolution. Upon adoption of such resolution, the City Engineer shall record a notice of acceptance, in a form to be approved by the City Attorney, in the Official Records of Sonoma County. 4.19. Warranty Period; Repair and Reconstruction. Without limiting the foregoing, Developer expressly warrants and guarantees all work performed under this Agreement and ail materials used in the Work for a period of one (1) year after the date of recordation of the notice of acceptance of the improvements in accordance with Section 4.18. If, within this one (1) year period, any Improvement or part of any Improvement installed or constructed, or caused to be installed or constructed by Developer, or any of the work done under this Agreement, fails to fulfill any of the requirements of the hnprovement Plans or this Agreement, Developer shall, without delay and without cost to City, repair, replace or reconstruct any defective or otherwise unsatisfactory part or parts of the Work or Improvement to the satisfaction of the City Engineer. Should Developer fail to act promptly, by failing to repair, replace or reconstruct work thirty (30) days after notification by City, or in accordance with this requirement, or should the exigencies of the situation require repairs, replacements or reconstruction to be made before Developer can be notified, City may, at its option, make the necessary repairs, replacements or perform the necessary reconstruction and Developer shall pay to the City upon demand the actual cost of such repairs, replacements or reconstruction. 4.20. Record Dtaw fts_. Upon completion of the Improvements and prior to final acceptance by the City Council, Developer shall deliver to City one electronic file, in a format specified by the City Engineer, and one mylar copy of "as -built" drawings. These drawings shall be in a form acceptable to the City Engineer, shall be certified by an engineer licensed by the State of 9 California as to accuracy and completeness, and shall reflect the Improvements as actually constructed, with any and all changes incorporated therein. Developer shall be solely responsible and liable for ensuring the completeness and accuracy of the record drawings. 4.21. Ownership of Improvements. From and after acceptance of the Improvements by formal action of the City Council, ownership of the Improvements shall be vested exclusively in City. 5. Security - 5.1 Performance Labor and Materials and Warranty Secln'it . In accordance with Sections 16.16.060 through 16.16.070 of the Rohnert Park Municipal Code, Developer will furnish and deliver to City, within the times set forth below, the following surety bonds, each of which must be issued by a surety company duly and regularly authorized to do general surety business in the State of California, or an irrevocable assignment of funds or letter of credit as may be acceptable to the City Attorney. 5.1.1 Performance Securit. Developer shall furnish and deliver labor and materials security concurrently with the execution of this Agreement which security must meet the requirements of Government Code Section 66499.2, if applicable, and Rohnert Park Municipal Code Section 16.16.070 and be acceptable to the City Attorney, in the amounts below: a) Kingwood Road and Knight Road Backbone Landscape Improvements: Seventy Three Thousand, Eight Hundred Dollars and Zero Cents ($73,800) b) Phase 2-13, 2-C, and 2-D and Hinebaugh Creek Trail Phase Two Landscape Improvements: Four Hundred Thirty Thousand, Three Hundred Forty Dollars and Zero Cents ($430,340.00) The Developer may utilize bonds posted for the Public Improvement Agreement for Vast Oak East Surface and Dry Utility Improvements with the University District LLC and Vast Oak L.P., and the Public Improvement Agreement for Vast Oak East Backbone Surface and Dry Utility Improvements with the University District LLC and Vast Oak L.P., in meeting this requirement, as those bonds include the cost of the Vast Oak East In -Tract, Backbone, and Hinebaugh Creek Trail Phase Two Landscaping Improvements. The security shall be conditioned upon the faithful performance of this Agreement with respect to the Work and shall be released by the City effective upon the date of recordation of the notice of acceptance of the improvements as described in Section 4.18.2 and Developer's delivery of the Warranty Security described in Section 5.1.3. 5.1.2 Labor and Materials Security. Developer shall furnish and deliver labor and materials security concurrently with the execution of this Agreement which security must meet the requirements of Government Code Section 66499.2, if applicable, and Rohnert Park Municipal Code Section 16.16.070 and be acceptable to the City Attorney, in the amounts below: a) Kingwood Road and Knight Road Backbone Landscape Improvements: Seventy Three Thousand, Eight Hundred Dollars and Zero Cents ($73,800) b) Phase 2-B, 2-C, and 2-D and Hinebaugh Creek Trail Phase Two Landscape Improvements: Four Hundred Thirty Thousand, Three Hundred Forty Dollars and Zero Cents ($430,340.00) 7 The Developer may utilize bonds posted for the Public Improvement Agreement for Vast Oak East Surface and Dry Utility Improvements with the University District LLC and Vast Oak L.P., and the Public Improvement Agreement for Vast Oak East Backbone Surface and Dry Utility Improvements with the University District LLC and Vast Oak L.P., in meeting this requirement, as those bonds include the cost of the Vast Oak East In -Tract, Backbone, and Hinebaugh Creek Trail Phase Two Landscaping Improvements. The security shall secure payment to the contractor(s) and subcontractor(s) performing the Work and to all persons furnishing labor, materials or equipment to them. The City shall retain each security until both (i) the City accepts the Work in accordance with Section 4.18 above and (ii) the statute of limitations to file an action under Civil Code section 3114 et seg. has expired. After said date, the security may be reduced by the City Engineer to an amount not less than the total amount claimed by all claimants for whom claims of lien have been recorded and notice given in writing to the City Council. The balance of the security shall be retained until the final settlement of all such claims and obligations. If no such claims have been recorded, the security shall be released in full by the City Engineer. 5.1.3. Warranty Security. Developer shall furnish and deliver warranty security in the amount specified in section 16.16.070 c. of the Rohnert Park Municipal Code., upon acceptance of the hnprovements and prior to release of the Performance Security, in the amounts below: a) Kingwood Road and Knight Road Backbone Landscape Improvements: Eleven Thousand, Seventy Dollars and Zero Cents ($11,070.00) b) Phase 2-13, 2-C, and 2-D and Hinebaugh Creek Trail Phase Two Landscape Improvements: Sixty Four Thousand, Five Hundred Fifty One Dollars and Zero Cents ($64,551.00) The security shall be in a form acceptable to the City Attorney and shall guarantee and warranty the Work for a period of one (1) year following the date of recordation of the notice of acceptance of the improvements against any defective work or labor done, or defective materials furnished. 5.2. Additional SM13•ity. If either upon execution of this Agreement or during the course of performance the City considers that it is necessary to have Developer post additional security, the City may require either a cash deposit or a surety bond guaranteeing performance in a form and signed by sureties satisfactory to it. The condition of the security shall be that if Developer fails to perform its obligation under this Agreement, the City may in the case of a cash bond act for it using the proceeds or in the case of a surety bond require the sureties to perform the obligations of the Agreement. 6. Indemnity and Insurance. 6.1 Indemnification. Developer agrees to indemnify, defend and hold the City, its elective and appointed boards, commissions, officers, agents, employees and consultants, harmless from and against any and all claims, liabilities, losses, damages or injuries of any kind (collectively, "Claims") arising out of Developer's, or Developer's contractors', subcontractors', agents' or employees', acts, omissions, or operations under this Agreement, including, but not limited to, the performance of the Work, whether such acts, omissions, or operations are by Developer or any of Developer's contractors, subcontractors, agents or employees, except to the extent such Claims are caused by the sole negligence or willful misconduct of the City. This indemnification includes, without limitation, the payment of all penalties, fines, judgments, awards, decrees, attorneys' fees, and related costs or expenses, and the reimbursement of City, its elected officials, officers, employees, and/or agents for all legal expenses and costs incurred by each of them. The aforementioned indemnity shall apply regardless of whether or not City has prepared, supplied or approved plans and/or specifications for the Work or Improvements and regardless of whether any insurance required under this Agreement is applicable to any Claims. The City does not and shall not waive any of its rights under this indemnity provision because of its acceptance of the bonds or insurance required under the provisions of this Agreement. Developer's obligation to indemnify City shall survive the expiration or termination of this Agreement. Developer agrees to obtain executed indemnity agreements with provisions identical to those set forth here in this section from each and every contractor and sub -contractor or any other person or entity involved by, for, with or on behalf of Developer in the performance of this Agreement. In the event Developer fails to obtain such indemnity obligations from others as required here, Developer agrees to be fully responsible according to the terms of this section. Failure of City to monitor compliance with these requirements imposes no additional obligations on City and will in no way act as a waiver of any rights hereunder. 6.2. Insurance. Developer shall maintain Commercial General Liability Insurance protecting the City from incidents as to bodily injury liability and property damage liability that may occur as a result of the Work and additional repairs. Developer shall provide certificate(s) of insurance and endorsements to City before any Work commences. The insurance policy shall contain, or be endorsed to contain, the following provisions: (1) The City, its officers, elected officials, employees, consultants, agents and volunteers are to be covered as additional insured's as respects to liability arising out of activities performed by or on behalf of Developer. The coverage shall contain no special limitations on the scope of protection afforded to the City, its officers, elected officials, employees, consultants, agents and volunteers. (2) The amounts of public liability and property damage coverage shall not be less than $3,000,000 (Three Million Dollars) per occurrence for bodily injury, personal injury and property damage. (3) The insurance shall be maintained in full force until the work has been completed to the satisfaction of the City Engineer. (4) The insurance policy steal I provide for 30 days' notice of cancellation to the City. The policy shall not be cancelled earlier than nor the amount of coverage be reduced earlier than 30 days after the City receives notice from the insurer of the intent of cancellation or reduction. (5) Any failure to comply with the reporting provisions of the policy shall not affect the coverage provided to the City, its officers, elected officials, employees, consultants, agents and volunteers. (6) Developer's insurance coverage shall be primary insurance as respects the City, its officers, elected officials, employees, consultants, agents and volunteers. Any insurance or self-insurance maintained by the City, its officers, elected officials, employees, consultants, agents and volunteers shall be in excess of Developer's insurance and shall not contribute to it. (7) Any deductibles or self-insured retentions must be declared to and approved by City. At the option of City, either: (a) the insurer shall reduce or eliminate such 0 deductibles or self-insured retentions as respects City, its elected officials, officers, employees, agents, and volunteers; or (b) Developer and its contractors shall provide a financial guarantee satisfactory to City guaranteeing payment of losses and related investigation costs, claims, and administrative and defense expenses. (8) Developer and Developer's insurance company agree to waive all rights of subrogation against City, its officers, elected officials, employees, agents and volunteers for losses paid under Developer's workers' compensation insurance policy which arise from the work performed by Developer. In the event that Developer's insurance is cancelled, Developer shall provide replacement coverage or all work must cease as of the cancellation date until replacement insurance coverage is provided. 6.3. Workers' Compensation Insurance. Developer shall provide, or cause to be provided, Workers' Compensation insurance as required by law, and shall cause its contractors and their subcontractors, agents and representatives to also maintain Workers' Compensation insurance as required by law. No Work shall commence until such Workers' Compensation insurance is obtained and in frill force and effect. 6.4. Other Insurance Reg irements. Developer shall: (1) Prior to taking any actions under this Agreement, furnish City with properly executed certificates of insurance which shall clearly evidence all insurance required in this section and provide that such insurance shall not be canceled, allowed to expire or be materially reduced in coverage except on thirty (30) days prior written notice to City. (2) Provide to City certified copies of endorsements and policies if requested by City, and properly executed certificates of insurance evidencing the insurance required herein. (3) Replace or require the replacement of certificates, policies and endorsements for any insurance required herein expiring prior to completion and acceptance of the Improvements. (4) Maintain all insurance required herein from the time of execution of this Agreement until the acceptance of the Improvements. (5) Place all insurance required herein with insurers licensed to do business in California. Breach of Agreement; Opportunity to Cure, Remedies. 7.1. Notice of Breach and Default. The occurrence of any of the following constitutes a breach and default of this Agreement: (1) Developer refuses or fails to complete the Work within the time set forth herein or abandons the Work. (2) Developer assigns the Agreement without the prior written consent of City. 10 (3) Developer is adjudged bankrupt or makes a general assignment for the benefit of creditors, or a receiver is appointed in the event of Developer's insolvency. (4) Developer or Developer's contractors, subcontractors, agents or employees, fail to comply with any terms or conditions of this Agreement. (5) Any delay in the construction of any portion of the Work or repairs, which in the reasonable opinion of the City Engineer, endangers public or private property. The City may serve written notice of breach and default upon Developer and the financial institution holding the security. 7.2. Breach of Agreement*. Performance by City. If the City gives Developer notice, under Section 7. 1, of breach and default of this Agreement, the City may proceed to complete the Work by contract or other method the City considers advisable, at the sole expense of Developer. Developer, immediately upon demand, shall pay the costs and charges related to the Work and any subsequent repairs. City, without liability for doing so, may take possession of and utilize in completing the Work and repairs, if any, such materials and other property belonging to Developer as may be on or about the Property and necessary for completion of the work. In the event of default, the financial institution holding the security shall be liable to City to pay the face amount of the bonds, as specified under Section 5. 7.3. Remedies. City may bring legal action to compel performance of this Agreement and recover the costs of completing the Work and/or repairs, if any, including City's administrative and legal costs. Developer agrees that if legal action is brought by City under this section of the Agreement, Developer shall pay all of the costs of suit; reasonable attorney fees, arbitration costs and such other costs as may be determined by the court or arbitrator. No failure on the part of City to exercise any right or remedy hereunder shall operate as a waiver of any other right or remedy that City may have hereunder. Miscellaneous. 8.1 Compliance with Laws. Developer shall fully comply with all federal, state and local laws, ordinances and regulations in the performance of this Agreement. Developer shall, at its own cost and expense, obtain all necessary permits and licenses for the Work, give all necessary notices, pay all fees and taxes required by law and make any and all deposits legally required by those public utilities that will serve the development on the Property. Copies and/or proof of payment of said permits, licenses, notices, fee and tax payments and deposits shall be furnished to the City Engineer upon request. 8.2. Notices. Formal written notices, demands, correspondence and communications between City and Developer shall be sufficiently given if: (a) personally delivered; or (b) dispatched by next day delivery by a reputable carrier such as Federal Express to the offices of City and Developer indicated below, provided that a receipt for delivery is provided; or (c) if dispatched by fust class mail, postage prepaid, to the offices of City and Developer indicated below. Such written notices, demands, correspondence and communications may be sent in the same manner to such persons and addresses as either party may from time -to -time designate by next day delivery or by mail as provided in this section. City: City of Rohnert Park 130 Avram Avenue Rohnert Park, CA 94928 Attn: City Manager with a copy to: City of Rohnert Park 11 130 Avram Avenue Rohnert Park, CA 94928 Attn: City Attorney ©evelgper: University District LLC, 500 La Gonda Way, #100 Danville, CA 94526 Attn. Devin Pohlson Notices delivered by deposit in the United States mail as provided above shall be deemed to have been served two (2) business days after the date of deposit if addressed to an address within the State of California, and three (3) business days if addressed to an address within the United States but outside the State of California. 8.3 Attorney Fees. Should any legal action or arbitration be brought by either party because of breach of this Agreement or to enforce any provision of this Agreement, the prevailing party shall be entitled to all costs of suit; reasonable attorney fees, arbitration costs and such other costs as may be determined by the court or arbitrator. 8.4. Entire Agreement. The terms and conditions of this Agreement constitute the entire agreement between City and Developer with respect to the matters addressed in this Agreement. This Agreement may not be altered, amended or modified without the written consent of both parties hereto. 8.5. Runs with the Land; Recordation. This Agreement pertains to and shall run with the Property. Upon execution, this Agreement shall be recorded in the Official Records of Sonoma County. 8.6. Transfers: Assignments. Developer may assign its obligations under this Agreement to successor owner(s) of the Site with the prior written approval of the City. In connection with any such assignment, Developer and its assignee shall execute and deliver to City a written assignment and assumption agreement in a form acceptable to the City Attorney. 8.7. Time is of the Essence. Time is of the essence of this Agreement and of each and every term and condition hereof. 8.8. Severability. If any provision of this Agreement is held, to any extent, invalid, the remainder of this Agreement shall not be affected, except as necessarily required by the invalid provision, and shall remain in full force and effect. 8.9. Waiver or Modification. Any waiver or modification of the provisions of this Agreement must be in writing and signed by the authorized representative(s) of each Party. 8.10. Reiationshii) of the Pailies. Neither Developer nor Developer's contractors, subcontractors, agents, officers, or employees are agents, partners, joint venturers or employees of City and the Developer's relationship to the City, if any, arising herefrom is strictly that of an independent contractor. Developer's contractors and subcontractors are exclusively and solely under the control and dominion of Developer. Further, there are no intended third party beneficiaries of any right or obligation assumed by the Parties. 12 8.11. Biadin = Upon Heirs. Successors and Assigns. The terms, covenants and conditions of this Agreement shall be binding upon all heirs, successors and assigns of the parties hereto; provided, however, that this Agreement shall not be binding upon a purchaser or transferee of any portion of the Property unless this Agreement has been assigned pursuant to Section 8.6, in which event this Agreement shall remain binding upon Developer. 8.12. Governing Law; . This Agreement shall be construed and enforced in accordance with the laws of the State of California, without reference to choice of law provisions. Any legal actions under this Agreement shall be brought only in the Superior Court of the County of Sonoma, State of California. 8.13. Counterparts. This Agreement may be executed in multiple counterparts, each of which shall be deemed to be an original. 8.14. Interpretation. This Agreement shall be construed according to its fair meaning, and not strictly for or against any party. No presumptions or rules of interpretation based upon the identity of the party preparing or drafting the Agreement, or any part thereof, shall apply to the interpretation of this Agreement. 8.15. Heading . Section headings in this Agreement are for convenience only and are not intended to be used in interpreting or construing the terms, covenants or conditions contained in this Agreement. 8.16 Authority. Each party executing this Agreement on behalf of a party represents and warrants that such person is duly and validly authorized to do so on behalf of the entity it purports to bind and if such party is a partnership, corporation or trustee, that such partnership, corporation or trustee has full right and authority to enter into this Agreement and perform all of its obligations hereunder. 8.17 Joint and Several Liability. University District and Vast Oak agree to and shall be jointly and severally liable for all obligations of Developer under this Agreement. IN WITNESS WHEREOF, City and Developer have executed this Agreement as of the Effective Date. Signatures on Next Page 13 "CITY" CITY OF ROHNERT PARK, a California municipal corporation Dated: City Manager Per Resolution No. 2017- adopted by the Rohnert Park City Council at its meeting of November 14, 2017. ATTEST: City Clerk APPROVED AS TO FORM: City Attorney 14 "DEVELOPER" University District LLC Dated: A Delaware Limited Liability Company By: Name: Title: Dated: 15 DEVELOPER" University District LLC A Delaware Limited Liability Company By: _ Name: Title: "DEVELOPER" Vast Oak LP A California Limited Partnership By: Name: Title: ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA ) ss, COUNTY OF SONOMA ) On before me, (here insert name and title of the office) personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) 16 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA ) ) ss. COUNTY OF CONTRA COSTA ) On _ before me, , (here insert name and title of the officer) personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal) 17 ACKNOWLEDGMENT A notary public or other officer completing this certificate verifies only the identity of the individual who signed the document to which this certificate is attached, and not the truthfulness, accuracy, or validity of that document. STATE OF CALIFORNIA ) ss. COUNTY OF SONOMA ) On before me, (here insert name and title of the officer) personally appeared , who proved to me on the basis of satisfactory evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted, executed the instrument. I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing paragraph is true and correct. WITNESS my hand and official seal. Signature (Seal)