2020/09/22 City Council Resolution 2020-088 RESOLUTION NO. 2020-088
A RESOLUTION OF THE CITY COUNCIL OF THE CITY OF ROHNERT PARK
APPROVING A PUBLIC IMPROVEMENT AND PUBLIC FACILITIE FEE AND
WATER CAPACITY CHARGE CREDIT AGREEMENT WITH KEISER 42 LLC, A
CALIFORNIA LIMITED LIABILITY COMPANY FOR A PORTION OF
KEISER AVENUE
WHEREAS, on May 23, 2006, the City Council of the City of Rohnert adopted
Resolution No 2006-141 approving the Final Environmental Impact Report (EIR) for the
University District Specific Plan Area including a draft EIR, a recirculated draft EIR, response to
comments, changes, clarifications, and corrections to the draft EIR and recirculated draft EIR and
appendices (together the "2006 EIR"); and
WHEREAS, on April 8, 2014, the City Council of the City of Rohnert Park adopted
Resolution No. 2014-032 approving an addendum to the 2006 EIR(together with the 2006 EIR
collectively called the "Updated Final EIR"); and
WHEREAS, on August 14, 2018, the City Council of the City of Rohnert Park adopted
Resolution 2018-112 approving the Tentative Map for the Bristol Development(Gee Property),
prepared by MacKay & Somps and dated November 2017 (the "Tentative Map"), subject to
certain conditions of approval ("Conditions of Approval"); and
WHEREAS, the Developer intends to file the Final Map for the Bristol Development,
consisting of 42 single-family residential lots; and
WHEREAS, the Conditions of Approval include requirements for Developer to
reconstruct the portion of Keiser Avenue that is necessary to support access to the development;
and
WHEREAS, utilizing funding generated by it Public Facilities Fee and Water Capacity
Charge programs, the City has prepared plans and specifications for the reconstruction of Keiser
Avenue that have been approved by the Deputy City Engineer and are in conformance with the
Conditions of Approval; and
WHEREAS,the Developer has posted performance and labor and materials bonds in the
amount of Five Hundred One Thousand Three Hundred Fifty Two Dollars and No Cents
($501,352.50) for the Keiser Avenue Improvements which includes the installation of fire
hydrants on the water system, installation of a recycled water main and surface improvements to
Keiser Avenue; and
WHEREAS,the City and Developer desire to enter into a Public Improvement and
Public Facilities Fee and Water Capacity Charge Credit Agreement for the Keiser Avenue
Improvements to more thoroughly define the terms and conditions of the construction and
dedication obligations under the conditions of approval and the City's intent to provide credit for
installation of eligible facilities in its Public Facilities Fee and Water Capacity Charge programs.
NOW,THEREFORE,BE IT RESOLVED that based on the evidence presented at the
duly noticed public meeting of September 22, 2020, the City Council of the City of Rohnert Park
finds that the public improvements and activities were adequately described and mitigated in the
University District Specific Plan Area Updated Final EIR, and that no other CEQA analysis is
warranted.
BE IT FURTHER RESOLVED by the City Council of the City of Rohnert Park that it
does hereby approve and authorize the execution by the City Manager of the Public
Improvement and Public Facilities Fee and Water Capacity Charge Credit Agreement by and
between the City of Rohnert Park, a municipal corporation, and Keiser 42 LLC, a California
Limited Liability Company for a portion of the Keiser Avenue (the "Improvement Agreement")
in substantially similar form to the agreement attached hereto as Exhibit"A," subject to minor
modifications by the City Manager or City Attorney.
BE IT FURTHER RESOLVED that the City Manager is hereby authorized and directed
to take all actions necessary to effectuate the terms of the Improvement Agreement.
DULY AND REGULARLY ADOPTED this 22nd day of September 2020.
CITY OF ROHNERT PARK
r/
Joseph T. Callinan, Mayor
ATTEST:
Sylvia Lopez Cuevas, City Clerk
Attachments: Exhibit A
ADAMS: 11r-
BELFORTE: td STAFFORD:A Yst 1r MACKENZIE: CALLINAN
AYES: ( NOES: ( ) ABSENT: ( ) ABSTAIN )
tC-
Resolution 2020-088
2
Exhibit A to Resolution
RECORDING REQUESTED BY
AND WHEN RECORDED MAIL TO:
City of Rohnert Park
130 Avram Avenue
Rohnert Park, California 94928-2486
Attention: City Clerk
)
)
)
)
)
)
)
)
(Space Above This Line for Recorder's Use Only)
Exempt from recording fee per Gov. Code § 27383.
PUBLIC IMPROVEMENT AND PUBLIC FACILITIES FEE AND WATER CAPACITY
CHARGE CREDIT AGREEMENT
BY AND BETWEEN THE CITY OF ROHNERT PARK
AND KEISER 42 LLC, A CALIFORNIA LIMITED LIABILITY COMPANY FOR A PORTION
OF KEISER AVENUE
This Public Improvement and Reimbursement Agreement (the "Agreement") is made and entered into on
this ______ day of ______________ 2020 (the "Effective Date") by and between Keiser 42 LLC, a
California Limited Liability Company ("Developer"), and the CITY OF ROHNERT PARK, a California
municipal corporation ("City"). City and Developer are sometimes referred to hereinafter individually as
“Party” and collectively as “Parties”.
RECITALS
A. On August 14, 2018, the City Council of the City of Rohnert Park adopted Resolution
No. 2018-112, appr oving the Tentative Map and Development Area Plan for the Bristol Development
(Gee Property), prepared by MacKay & Somps and dated November 2017 (the "Tentative Map"), subject
to certain conditions of approval (the "Conditions").
B. The Conditions require that the Developer provide improvements to Keiser Avenue as
necessary for access to its development (the “Improvements”).
C. With funding from its Public Facilities Fee Program, the City has prepared plans,
specifications and drawings for the Improvements (the “Improvement Plans”). These plans are on file in
the office of the City Engineer and have been approved as outlined below:
• City of Rohnert Park, Keiser Avenue Reconstruction Project - Phase 2, Snyder Lane to
Kerry Road (Portion), Project # 2017-18, prepared by GHD Inc, dated June 1, 2020, 58
sheets.
D. Developer intends to file the final map for the Bristol Development, consisting of 42
single-family residential lots (the “Project”) and wishes to begin the construction of the Bristol
infrastructure in advance of filing the maps.
E. City and Developer desire to enter an agreement providing for the construction and
installation of the Improvements in accordance with the plans, specification and drawings described in
Recital C.
2
AGREEMENT
NOW, THEREFORE, in consideration of the faithful performance of the terms and
conditions set forth in this Agreement, the parties hereto agree as follows:
1. Incorporation of Recitals. The foregoing Recitals are true and correct and, together
with the Project approvals and the requirements of Chapter 16.16 of the RPMC, are hereby
incorporated into and form a material part of this Agreement.
2. Purpose and Effective Date
2.1 Purpose. The purpose of this Agreement is to guarantee completion of the
Improvements and ensure satisfactory performance by Developer of Developer's obligations to satisfy the
Conditions for the Project.
2.2 Effective Date. The Effective Date of this Agreement shall be as set forth above.
3. Property Subject to Agreement. The property which is the subject of this Agreement is
located in the City of Rohnert Park, Sonoma County, California, and is described in Exhibit A, attached
hereto (the “Property”).
4. Improvements
4.1 Duty to Install Improvements. Developer will construct, install and complete, or
cause to be constructed, installed and completed, at the Developer's sole cost and expense, the
Improvements, in accordance with the Improvement Plans (defined in Recital C. above) and to the
satisfaction of the City Engineer, in his/ her reasonable discretion. Developer will also supply all labor
and materials therefor, all in strict accordance with the terms and conditions of this Agreement. The
construction, installation and completion of the Improvements including all labor and materials furnished
in connection therewith are hereinafter referred to collectively as the "Work."
City shall not be responsible or liable for the maintenance or care of the Improvements until City formally
approves and accepts them in accordance with its policies and procedures. City shall exercise no control
over the Improvements until approved and accepted. Any use by any person of the Improvements, or any
portion thereof, shall be at the sole and exclusive risk of the Developer at all times prior to City’s
acceptance of the Improvements. Developer shall maintain all the Improvements in a state of good repair
until they are completed by Developer and approved and accepted by City. Maintenance shall include, but
shall not be limited to, repair of pavement, curbs, gutters, parkways, water mains, and sewers; weed
control; removal of debris from sewers and storm drains; and sweeping, repairing, and maintaining in
good and safe condition all streets and street improvements. It shall be Developer’s responsibility to
initiate all maintenance work, but if it shall fail to do so, it shall promptly perform such maintenance work
when notified to do so by City. If Developer fails to properly prosecute its maintenance obligation under
this section, City may do all work necessary for such maintenance and the cost thereof shall be the
responsibility of Developer and its surety under this Agreement. Prior to undertaking said maintenance
work, City agrees to notify Developer in writing of the deficiencies and the actions required to be taken
by the Developer to cure the deficiencies. Developer shall have thirty (30) days from the date of the
notice within which to correct, remedy or cure the deficiency. If the written notification states that the
problem is urgent and relates to the public health and safety, then the Developer shall have twenty-four
(24) hours to correct, remedy or cure the deficiency. City shall not be responsible or liable for any
damages or injury of any nature in any way related to or caused by the Improvements or their condition
prior to acceptance.
3
4.2. Completion Date. Developer will complete the Work within one year of the
Effective Date or as required by the Conditions of Approval for the Bristol Property, whichever is sooner.
All Work will be completed in a good and workmanli ke manner in accordance with accepted design and
construction practices. This completion date may be extended by the City in its sole and absolute
discretion at the request of Developer, which request shall be accompanied by a written assurance
acceptable to the City Attorney that the securities required by Section 5 shall remain enforceable
throughout the term of the extension.
4.3. Estimated Cost of Work. The estimated cost of the Work is Five Hundred One
Thousand Three Hundred Fifty Two Dollars and Fifty Cents ($501,352.50).
Notwithstanding this estimate, Developer hereby acknowledges and agrees that (a) the
actual costs to complete the Work may significantly exceed this estimate, (b) this estimate in no way
limits Developer’s financial obligation, and (c) that Developer is obligated to complete the Work at its
own cost, expense, and liability.
4.4. Modifications to the Plans. Approval of this Agreement by City does not release
Developer of its responsibility to correct mistakes, errors or omissions in the Improvement Plans. If, at
any time, in the opinion of the City Engineer, in his /her reasonable discretion, the Improvement Plans are
deemed inadequate in any respect Developer agrees to make such modifications, changes or revisions as
necessary in order to complete the Work in a good and workmanlike manner in accordance with accepted
design and construction standards.
4.5. Foreman or Superintendent. Developer shall give personal attention to the Work.
A competent foreman or superintendent, satisfactory to the City Engineer, in his/her reasonable
discretion, with authority to act for and on behalf of Developer, shall be named in writing by Developer
prior to commencement of the Work, shall be present on the Property during the performance of the
Work. Any c hange in the superintendent will require advance notification to the City Engineer and
concurrence of the City Engineer and the Engineer of Record for the Improvement Plans .
4.6. Encroachment Permits. Developer shall obtain, at its sole cost and expense, any
encroachment permits required by the City in order to perform the Work.
4.7. Inspection: All of the Improvements shall be constructed and installed to the
satisfaction of the City Engineer, in his or her reasonable discretion. City and its authorized ag ents shall,
at all times during the construction of the Improvements, have free access to the Improvements and shall
be allowed to examine and inspect the Improvements and all material used and to be used in the
Improvements to confirm compliance with City Plans and Specifications.
4.8. Commencement of Construction and Inspection. Developer and its contractor
or subcontractors shall not commence construction of the Improvements until Developer has received
written authorization from City to proceed. Written authorization shall be in the form of signed
approved plans along with permit issuance, including any encroachment permit required to carry on
construction activities in the City's right -of-way as described in Section 4 .6. All work performed on
the Improvements shall be done in strict compliance with the City approved plans, specifications and
the contract documents and in a good and workmanlike manner. All work performed by Developer,
its contractor or agents to construct the Improvements shall be subject to inspection by City. All fees
and costs to construct the Improvements shall be borne solely by Developer (including the applicable
Inspection Fee in accordance with the City's adopted Engineering Fee Schedule). Inspection by City
or its employees or agents shall not relieve Developer of its liability for design defects or improper
or inadequate workmanship.
4
4.9. City's Inspection, Administration and Testing Costs. In accordance with its
Reimbursement Agreement with the City, Developer shall pay to City the actual cost for all inspection,
administration and testing services furnished by City in connection with this Agreement, including those
performed by consultants under contract with the City (the "City Costs"). City agrees not to double charge
Developer (through the imposition of both a processing fee and a consultant charge) for any individual
monitoring, inspection, testing or evaluation service. In addition, City agrees to limit its use of outside
consultants to those reasonably necessary or desirable, as determined by the City Manager or his/her
designee in his/her reasonable discretion, to accomplish the requisite inspection, administration and
monitoring.
4.10. No Waiver by City. Inspecting of the work and/or materials, or approval of work
and/or materials, or a statement by an officer, agent or employee of the City indicating the work complies
with this Agreement, or acceptance of all or any portion of the work and/or materials, or payments
thereof, or any combination of all of these acts shall not relieve Developer or its obligation to fulfill this
Agreement; nor is the City by these acts prohibited from bringing an action for damages arising from the
failure to comply with this Agreement.
4.11. Erosion Control. Pursuant to Rohnert Park Municipal Code Chapter 15.52,
Developer shall be responsible for the control of erosion on the Property and shall prevent its entry into
the storm drainage system.
4.12. Prevailing Wages. The work of the Improvements constitutes a "public work"
as defined in the California Labor Code, section 1771, et seq ("Labor Code Regulations") because
the work is being paid for in whole or in part out of public funds. City and Developer acknowledge
that the construction of the Improvements is subject to the payment of prevailing wages . Further,
Developer agrees to defend, indemnify and hold City, its elected officials, officers, employees, and
agents free and harmless from any and all claims, damages, suits or actions arising out of or
incident to Developer's obligations under this section and the payment of prevailing wages.
4.13. Contractor Licenses. All work performed on the Improvements shall be
done only by contractors licensed in the State of California and qualified to perform the type of
work required and comply with the City's Business License Ordinance.
4.14. Repair of Work Damaged During Construction. Developer agrees to repair or
have repaired in a timely manner at its sole cost and expense all public roads, streets, or other public or
private property damaged as a result of or incidental to the Work or in connection with the development
of the Property or to pay to the property owner of any damaged road, street or property the full cost of
such repair. In addition, Developer shall obtain the written acceptance of such repair or payment from any
owner whose private property was repaired by Developer or to whom Developer has paid the full cost of
such repair in accordance with this Section 4.14. City shall be under no obligation whatsoever to accept
the Work completed un der this Agreement until such time as all repairs have been completed or have
been paid for and written acceptances have been provided to the City Engineer, except as otherwise
provided in section 4.18.1
4.15. Payments. Developer agrees that it will pay, when due, all those furnishing labor
or materials in connection with the Work. Developer further agrees that pursuant to Government Code
section 66499.7, the Labor and Materials Bond provided by Developer in accordance with Section 5.1.2
of this Agreement shall not be released if any mechanics liens or stop notices are outstanding, unless said
liens are released by bond in compliance with Civil Code section 3143.
5
4.16. Liability for Work Prior to Formal Acceptance. Until the City Council has
formally accepted the Improvements, Developer shall be solely responsible for all damage to the
work, regardless of cause, and for all damages or injuries to any person or property at the work
site, except damage or injury due to the sole negligence of City, or its employees. Developer shall
replace or repair any portion of the Improvements that have been destroyed or damaged prior to
final acceptance of completed work by the City Council or the City Engineer. Any such repair or
replacement shall be to the satisfaction and subject to the approval of the City Engineer. Developer
shall repair to the satisfaction of the City Engineer any damage to the utilities systems, concrete
work, street paving or other public improvements that may occur in connection with the
Improvements work.
4.17. Completion of Work. After Developer (a) completes the Work in accordance
with the Improvement Plans and the terms and conditions of this Agreement, (b) repairs any road, street,
or private or public property damaged as a result of the Work or pays the full cost of such repair to the
owner whose property was damaged and (c) obtains the written acceptance of such repair or payment
from any owner whose private property was repaired by Developer or to whom Developer paid the full
cost of such repair, Developer will provide City with a written notice of completion, together with copies
of all written acceptances.
4.18. Final Acceptance.
4.18.1 Notice of Completion. Within thirty (30) days of receipt of Developer's
written notification pursuant to Section 4.17 above, City Engineer shall inspect the Work and repairs and
review the written acceptances, if any, and send Developer a written notice stating whether the Work and
repair are complete to the satisfaction of the City Engineer, in his/her reasonable discretion, and whether
the written acceptances have been provided. If the Work and repair are, in the opinion of the City
Engineer, not complete and satisfactory, and/or written acceptances have not been provided, the City
Engineer will list the deficiencies that must be corrected to find the Work and repair complete and
satisfactory. Upon satisfactory completion of the Work and repair and submittal of written acceptances,
the City Engineer will send Developer a written notice of satisfactory completion. The requirement for
written acceptances may be waived by the City Engineer, in his/her reasonable discretion, if Developer
has made commercially reasonable efforts to obtain such acceptances. City Engineer's failure to respond
to Developer's written notification within thirty (30) days will not be deemed a breach or default under
this Agreement.
4.18.2 Acceptance of Improvements. After sending Developer a written notice
of satisfactory completion pursuant to Section 4.18.1, the City Engineer will recommend acceptance of
the Improvements, or a portion thereof, to the City Council. In conjunction with such recommendation,
the City Engineer will recommend the acceptance of the offers of dedication shown on the final map for
the Property. The acceptance of the Improvements, offers of dedication and right-of-way and easements,
if any, shall be by resolution. Upon adoption of such resolution, the City Engineer shall record a notice of
acceptance, in a form to be approved by the City Attorney, in the Official Records of Sonoma County.
4.19. Warranty Period; Repair and Reconstruction. Without limiting the foregoing,
Developer expressly warrants and guarantees all work performed under this Agreement and all materials
used in the Work for a period of one (1) year after the date of recordation of the notice of acceptance of
the improvements in accordance with Section 4.18. If, within this one (1) year period, any Improvement
or part of any Improvement installed or constructed, or caused to be installed or constructed by
Developer, or any of the work done under this Agreement, fails to fulfill any of the requirements of the
Improvement Plans or this Agreement, Developer shall, without delay and without cost to City, repair,
replace or reconstruct any defective or otherwise unsatisfactory part or parts of the Work or Improvement
6
to the satisfaction of the City Engineer. Should Developer fail to act promptly, by failing to repair, replace
or reconstruct work thirty (30) days after notification by City, or in accordance with this requirement, or
should the exigencies of the situation require repairs, replacements or reconstruction to be made before
Developer can be notified, City may, at its option, make the necessary repairs, replacements or perform
the necessary reconstr uction and Developer shall pay to the City upon demand the actual cost of such
repairs, replacements or reconstruction.
4.20. Record Drawings. Upon completion of the Improvements and prior to final
acceptance by the City Council, Developer shall deliver to City one electronic file, in a format
specified by the City Engineer, and one mylar copy of "as-built" drawings. These drawings shall be
in a form acceptable to the City Engineer, shall be certified by an engineer licensed by the State of
California as to accuracy and completeness, and shall reflect the Improvements as actually
constructed, with any and all changes incorporated therein. Developer shall be solely responsible
and liable for ensuring the completeness and accuracy of the record drawings.
4.21. Ownership of Improvements. From and after acceptance of the
Improvements by formal action of the City Council, ownership of the Improvements shall be
vested exclusively in City.
5. Security.
5.1 Performance, Labor and Materials and Warranty Security. In accordance with
Sections 16.16.060 through 16.16.070 of the Rohnert Park Municipal Code, Developer will furnish and
deliver to City, within the times set forth below, the following surety bonds, each of which must be issued
by a surety company duly and regularly authorized to do general surety business in the State of California,
or an irrevocable assignment of funds or letter of credit as may be acceptable to the City Attorney.
5.1.1 Performance Security. Developer shall furnish and deliver performance security
concurrently with the execution of this Agreement, which must meet the requirements of Government
Code Section 66499.1, if applicable, and Rohnert Park Municipal Code Section 16.16.070 and be
acceptable to the City Attorney, in the amount of Five Hundred One Thousand Three Hundred Fifty Two
Dollars and Fifty Cents ($501,352.50).
The security shall be conditioned upon the faithful performance of this Agreement with respect to the
Work and shall be released by the City effective upon the date of recordation of the notice of acceptance
of the improvements as described in Section 4.18.2 and Developer's delivery of the Warranty Security
described in Section 5.1.3.
5.1.2 Labor and Materials Security. Developer shall furnish and deliver labor and
materials security concurrently with the execution of this Agreement which security must meet the
requirements of Government Code Section 66499.2, if applicable, and Rohnert Park Municipal Code
Section 16.16.070 and be acceptable to the City Attorney, in the amount of Five Hundred One Thousand
Three Hundred Fifty Two Dollars and Fifty Cents ($501,352.50).
The security shall secure payment to the contractor(s) and subcontractor(s) performing the Work and to
all persons furnishing labor, materials or equipment to them. The City shall retain each security until both
(i) the City accepts the Work in accordance with Section 4.18 above and (ii) the statute of limitations to
file an action under Civil Code section 3114 et seq. has expired. After said date, the security may b e
reduced by the City Engineer to an amount not less than the total amount claimed by all claimants for
whom claims of lien have been recorded and notice given in writing to the City Council. The balance of
7
the security shall be retained until the final settlement of all such claims and obligations. If no such claims
have been recorded, the security shall be released in full by the City Engineer.
5.1.3. Warranty Security. Developer shall furnish and deliver warranty security in the
amount specified in sect ion 16.16.070 c. of the Rohnert Park Municipal Code., upon acceptance of the
Improvements and prior to release of the Performance Security, in the amount in the amount of Seventy
Five Thousand Two Hundred and Three Dollars and No Cents ($75,203.00).
The s ecurity shall be in a form acceptable to the City Attorney and shall guarantee and warranty the Work
for a period of one (1) year following the date of recordation of the notice of acceptance of the
improvements against any defective work or labor done, or defective materials furnished.
5.2. Additional Security. If either upon execution of this Agreement or during the
course of performance the City considers that it is necessary to have Developer post additional security,
the City may require either a cash deposit or a surety bond guaranteeing performance in a form and signed
by sureties satisfactory to it. The condition of the security shall be that if Developer fails to perform its
obligation under this Agreement, the City may in the case of a cash bond a ct for it using the proceeds or
in the case of a surety bond require the sureties to perform the obligations of the Agreement.
6. Indemnity and Insurance.
6.1 Indemnification. Developer agrees to indemnify, defend and hold the City, its
elective and appointed boards, commissions, officers, agents, employees and consultants, harmless from
and against any and all claims, liabilities, losses, damages or injuries of any kind (collectively, "Claims")
arising out of Developer's, or Developer's contractors', subcontractors', agents' or employees', acts,
omissions, or operations under this Agreement, including, but not limited to, the performance of the
Work, whether such acts, omissions, or operations are by Developer or any of Developer's contractors,
subcontractors, agents or employees, except to the extent such Claims are caused by the sole negligence
or willful misconduct of the City. This indemnification includes, without limitation, the payment of all
penalties, fines, judgments, awards, decrees, attorneys’ fees, and related costs or expenses, and the
reimbursement of City, its elected officials, officers, employees, and/or agents for all legal expenses and
costs incurred by each of them.
The aforementioned indemnity shall apply regardless of whether or not City has
prepared, supplied or approved plans and/or specifications for the Work or Improvements and regardless
of whether any insurance required under this Agreement is applicable to any Claims. The City does not
and shall not waive any of its rights und er this indemnity provision because of its acceptance of the bonds
or insurance required under the provisions of this Agreement. Developer’s obligation to indemnify City
shall survive the expiration or termination of this Agreement.
Developer agrees to obtain executed indemnity agreements with provisions identical to
those set forth here in this section from each and every contractor and sub-contractor or any other person
or entity involved by, for, with or on behalf of Developer in the performance of this Agreement. In the
event Developer fails to obtain such indemnity obligations from others as required here, Developer agrees
to be fully responsible according to the terms of this section. Failure of City to monitor compliance with
these requirements imposes no additional obligations on City and will in no way act as a waiver of any
rights hereunder.
6.2. Insurance. Developer shall maintain Commercial General Liability Insurance
protecting the City from incidents as to bodily injury liability and property damage liability that may
occur as a result of the Work and additional repairs. Developer shall provide certificate(s) of insurance
8
and endorsements to City before any Work commences. The insurance policy shall contain, or be
endorsed to contain, the following provisions:
(1) The City, its officers, elected officials, employees, consultants, agents and
volunteers are to be covered as additional insured’s as respects to liability arising
out of activities performed by or on behalf of Developer. The covera ge shall
contain no special limitations on the scope of protection afforded to the City, its
officers, elected officials, employees, consultants, agents and volunteers.
(2) The amounts of public liability and property damage coverage shall not be less
than $3,000,000 (Three Million Dollars) per occurrence for bodily injury,
personal injury and property damage.
(3) The insurance shall be maintained in full force until the work has been completed
to the satisfaction of the City Engineer.
(4) The insurance p olicy shall provide for 30 days’ notice of cancellation to the City.
The policy shall not be cancelled earlier than nor the amount of coverage be
reduced earlier than 30 days after the City receives notice from the insurer of the
intent of cancellation or reduction.
(5) Any failure to comply with the reporting provisions of the policy shall not affect
the coverage provided to the City, its officers, elected officials, employees,
consultants, agents and volunteers.
(6) Developer's insurance coverage shall be primary insurance as respects the City,
its officers, elected officials, employees, consultants, agents and volunteers. Any
insurance or self-insurance maintained by the City, its officers, elected officials,
employees, consultants, agents and volunteer s shall be in excess of Developer's
insurance and shall not contribute to it.
(7) Any deductibles or self -insured retentions must be declared to and approved by
City. At the option of City, either: (a) the insurer shall reduce or eliminate such
deductibles or self-insured retentions as respects City, its elected officials,
officers, employees, agents, and volunteers; or (b) Developer and its contractors
shall provide a financial guarantee satisfactory to City guaranteeing payment of
losses and related investigation costs, claims, and administrative and defense
expenses.
(8) Developer and Developer's insurance company agree to waive all rights of
subrogation against City, its officers, elected officials, employees, agents and
volunteers for losses paid under Developer's workers' compensation insurance
policy which arise from the work performed by Developer.
In the event that Developer's insurance is cancelled, Developer shall provide replacement coverage or all
work must cease as of the cancellation date until replacement insurance coverage is provided.
6.3. Workers' Compensation Insurance. Developer shall provide, or cause to be
provided, Workers' Compensation insurance as required by law, and shall cause its contractors and their
subcontractors, agents and representatives to also maintain Workers' Compensation insurance as required
9
by law. No Work shall commence until such Workers' Compensation insurance is obtained and in full
force and effect.
6.4. Other Insurance Requirements. Developer shall:
(1) Prior to taking any actions under this Agreement, furnish City with properly
executed certificates of insurance which shall clearly evidence all insurance
required in this section and provide that such insurance shall not be canceled,
allowed to expire or be materially reduced in coverage except on thirty (30)
days prior written notice to City.
(2) Provide to City certified copies of endorsements and policies if requested by City, and properly executed certificates of insurance evidencing the insurance required
herein.
(3) Replace or require the replacement of certificates, policies and endorsements for any insurance required herein expiring prior to completion and acceptance of the Improvements.
(4) Maintain all insurance required herein from the time of execution of this
Agreement until the acceptance of the Improvements.
(5) Place all insurance required herein with insurers licensed to do business in
Calif ornia .
7. Breach of Agreement; Opportunity to Cure; Remedies.
7.1. Notice of Breach and Default. The occur rence of any of the following constitutes
a breach and default of this Agreement:
(1) Developer refuses or fails to complete the Work within the time set forth herein
or abandons the Work.
(2) Developer assigns the Agreement without the prior written consent of City.
(3) Developer is adjudged bankrupt or makes a general assignment for the benefit of
creditors, or a receiver is appointed in the event of Developer's insolvency.
(4) Developer or Developer's contractors, subcontractors, agents or employees, fail
to comply with any terms or conditions of this Agreement.
(5) Any delay in the construction of any portion of the Work or repairs, which in the
reasonable opinion of the City Engineer, endangers public or private property.
The City may serve written notice of breach and default upon Developer and the financial institution
holding the security.
7.2. Breach of Agreement; Performance by City. If the City gives Developer notice,
under Section 7.1, of breach and default of this Agreement, the City may proceed to complete the Work
by contract or other method the City considers advisable, at the sole expense of Developer. Developer,
immediately upon demand, shall pay the costs and charges related to the Work and any subsequent
repairs. City, without liability for doing so, may take possession of and utilize in completing the Work
10
and repairs, if any, such materials and other property belonging to Developer as may be on or about the
Property and necessary for completion of the work. In the event of default, the financial institution
holding the security shall be liable to City to pay the face amount of the bonds, as specified under Section
5.
7.3. Remedies. City may bring legal action to compel performance of this Agreement
and recover the costs of completing the Work and/or repairs, if any, including City's administrative and
legal costs. Developer agrees that if legal action is brought by City under this section of the Agreement,
Developer shall pay all of the costs of suit; reasonable attorney fees, arbitration costs and such other costs
as may be determined by the court or arbitrator. No failure on the part of City to exercise any right or
remedy hereunder shall operate as a waiver of any other right or remedy that City may have hereunder.
8. Public Facilities Fee and Water Capacity Charge Credits .
8.1. Eligible Improvements. The Improvements eligible to receive the a fee credit (the
“Public Facilities Fee Credit”) described in this Section 8 are the installation of a recycled water main and
the surface improvements to Keiser Avenue from its intersection with Snyder Lane to approximately 640
feet east of its intersection with Snyder Lane. The Improvements eligible to receive the a charge credit
(the “Water Capacity Charge Credit ”) described in this Section 8 are the installation of two fire hydrants
along Keiser Avenue between its intersection with Snyder Lane and 600 feet east of its intersection with
Snyder Lane.
8.2. Source and Method of Credits. Subject to the limitations set forth in Section 8.6,
City shall credit Developer for the costs associated with the construction of the Keiser Avenue Surface
improvements and fire hydrant improvements as outlined in Exhibit B.
The Public Facilities Fee Credit represents reimbursement to the Developer for the costs
of the Keiser Avenue recycled water main and surface improvements that are covered by the Public
Facilities Fee, but which Developer has agreed to incur. The initial estimated total credit amount is
indicated under the "Public Facilities Fee Credit Calculation" heading in Exhibit B, attached hereto, and
shall be afforded to Developer in the form of a credit against the Public Facilities Fee that would
otherwise be applicable to the Project.
The Water Capacity Charge Credit represents reimbursement to the Developer for the
costs of the two fire hydrants that are covered by the Water Capacity Charge, but which Developer has
agreed to incur. The initial estimated total credit amount is indicated under the "Water Capacity Charge
Credit Calculation" attached hereto, and shall be afforded to Developer in the form of a credit against the
Water Capacity Charge that would otherwise be applicable to the Project
8.3. Implementation of the Credit s. Developer shall be entitled to receive both the
Public Facilities Fee Credit and the Water Capacity Charge Credit at the time of issuance of building
permits for the Bristol project. Such credit shall be personal to the Developer and shall not run to
successors and assigns unless expressly authorized to so run, in writing by the Developer.
8.4. Fee and Charge Obligation. Developer's obligation to pay the full amount of the
Public Facilities Fee and Water Capacity Charge for any development on the Bristol Project property
shall remain a debt and obligation of Developer until completion by Developer and acceptance of the
Improvements by City. In the event that the Improvements are not completed by a date two (2) years from
the Effective Date of this Agreement, any Public Facilities Fee or Water Capacity Charge previously
credited pursuant to this Agreement shall be immediately due and payable. If such fees and charges are
not paid as required, City may provide written notice to Developer of its default. If such default is not
11
corrected within 30 days from the date of written notice, Developer agrees that the amount of any unpaid
Public Facilities Fees and Water Capacity Charges may be placed upon the Bristol Project property as a
lien and special assessment. The assessment shall continue until it is paid, together with interest at the
legal maximum rate computed from the date of confirmation of the statement until payment. The
assessment shall be collected at the same time and in the same manner as ordinary municipal taxes are
collected, and shall be subject to the same penalties and procedure and sale in case of delinquency as is
provided for ordinary municipal taxes. All laws applicable to the levy, collection and enforcement of
municipal taxes shall be applicable to the special assessment. In addition, City may use any other
available legal means to collect the unpaid Public Facilities Fee and Water Capacity Charge and the
choice of one remedy does not affect City's ability to use alternative remedies.
8.5 Expiration of Credit Obligation. The Public Facilities Fee and Water Capacity
Charge Credit shall be granted to Developer at the time Developer obtains building permit(s) for the
Project. City's obligation to extend Developer a credit as described herein shall continue for a total of two
(2) years from the date the Developer begins construction of the Keiser Avenue surface improvements
and the fire hydrant improvements unless the obligation is sooner satisfied. If Developer fails to complete
the Improvements within the two-year time frame, City may seek payment of the Public Facilities Fee and
Water Capacity Charges from Developer as provided in Section 8.4, above.
8.6 Maximum Credit. The total amount of the Public Facilities Fee Credit obligation
for the Improvements shall be as determined by City in accordance with the City of Rohnert Park 2011
Update to the Public Facilities Finance Plan. The Parties acknowledge and agree that the maximum credit
amount for the Keiser Avenue surface improvements is Four Hundred Seventy Seven Thousand Three
Hundred Fifty Two Dollars and Fifty Cents ($477,352.50) as more fully described in Exhibit B.
The total amount of the Water Capacity Charge Credit is based on the City’s estimate of
construction costs. The Parties acknowledge and agree that the maximum credit amount for the fire
hydrant installations is Twenty Four Thousand Dollars and No Cents ($24,000.00) as more fully
described in Exhibit B.
8.7 Areas and Quantities . The areas and quantities used to develop th ese credits are
based on the information and plans available at this time. The actual area s and quantities may change at
the time of dedication to the City and/or construction by the Developer. If it is determined by the City
Engineer that the areas and quantities have changed, the credit amount may be adjusted
9. Miscellaneous.
9.1 Compliance with Laws. Developer shall fully comply with all federal, state and
local laws, ordinances and regulations in the performance of this Agreement. Developer shall, at its own
cost and expense, obtain all necessary permits and licenses for the Work, give all necessary notices, pay
all fees and taxes required by law and make any and all deposits legally required by those public utilities
that will serve the development on the Property. Copies and/or proof of payment of said permits, licenses,
notices, fee and tax payments and deposits shall be furnished to the City Engineer upon request.
9.2 Notices. Formal written notices, demands, correspondence and communications
between City and Developer shall be sufficiently given if: (a) personally delivered; or (b) dispatched by
next day delivery by a reputable carrier such as Federal Express to the offices of City and Developer
indicated below, provided that a receipt for delivery is provided; or (c) if dispatched by first class mail,
postage prepaid, to the offices of City and Developer indicated below. Such written notices, demands,
correspondence and communications may be sent in the same manner to such persons and addresses as
either party may from time-to-time designate by next day delivery or by mail as provided in this section.
12
City: City of Rohnert Park
130 Avram Avenue
Rohnert Park, CA 94928
Attn: City Manager
with a copy to: City of Rohnert Park
130 Avram Avenue
Rohnert Park, CA 94928
Attn: City Attorney
Developer: Keiser 42 LLC,
c/o Signature Homes, In c.
4670 Willow Road, Suite 200
Pleasanton, CA 94588
Attn. Stephen Miller
Notices delivered by deposit in the United States mail as provided above shall be deemed to have been
served two (2) business days after the date of deposit if addressed to an address within the State of
California, and three (3) business days if addressed to an address within the United States but outside the
State of California.
9.3 Attorney Fees. Should any legal action or arbitration be brought by either party
because of breach of this Agreement or to enforce any provision of this Agreement, the prevailing party
shall be entitled to all costs of suit; reasonable attorney fees, arbitration costs and such other costs as may
be determined by the court or arbitrator.
9.4 Entire Agreement. The terms and conditions of this Agreement constitute the
entire agreement between City and Developer with respect to the matters addressed in this Agreement.
This Agreement may not be altered, amended or modified without the written consent of both parties
hereto.
9.5 Runs with the Land; Recordation. This Agreement pertains to and shall run with
the Property. Upon execution, this Agreement shall be recorded in the Official Records of Sonoma
County.
9.6 Transfers; Assignments. Developer may assign its obligations under this
Agreement to successor owner(s) of the Site with the prior written approval of the City. In connection
with any such assignment, Developer and its assignee shall execute and deliver to City a written
assignment and assumption agreement in a form acceptable to the City Attorney.
9.7 Time is of the Essence. Time is of the essence of this Agreement and of each and
every term and condition hereof.
9.8 Severability. If any provision of this Agreement is held, to any extent, invalid,
the remainder of this Agreement shall not be affected, except as necessarily required by the invalid
provision, and shall remain in full force and effect.
9.9 Waiver or Modification. Any waiver or modification of the provisions of
this Agreement must be in writing and signed by the authorized representative(s) of each Party.
9.10 Relationship of the Parties. Neither Developer nor Developer's contractors,
subcontractors, agents, officers, or employees are agents, partners, joint venturers or employees of City
and the Developer's relationship to the City, if any, arising herefrom is strictly that of an independent
13
contractor. Developer’s contractors and subcontractors are exclusively and solely under the control and
dominion of Developer. Further, there are no intended third party beneficiaries of any right or obligation
assumed by the Parties.
9.11 Binding upon Heirs, Successors and Assigns. The terms, covenants and
conditions of this Agreement shall be binding upon all heirs, successors and assigns of the parties hereto;
provided, however, that this Agreement shall not be binding upon a purchaser or transferee of any portion
of the Property unless this Agreement has been assigned pursuant to Section 9.6, in which event this
Agreement shall remain binding upon Developer.
9.12 Governing Law; Venue. This Agreement shall be construed and enforced in
accordance with the laws of the State of California, without reference to choice of law provisions. Any
legal actions under this Agreement shall be brought onl y in the Superior Court of the County of Sonoma,
State of California.
9.13 Counterparts. This Agreement may be executed in multiple counterparts,
each of which shall be deemed to be an original.
9.14 Interpretation. This Agreement shall be construed according to its fair
meaning, and not strictly for or against any party. No presumptions or rules of interpretation based
upon the identity of the party preparing or drafting the Agreement, or any part thereof, shall apply
to the interpretation of this Agreeme nt.
9.15 Headings. Section headings in this Agreement are for convenience only and are
not intended to be used in interpreting or construing the terms, covenants or conditions contained in this
Agreement.
9.16 Authority. Each party executing this Agreement on behalf of a party represents
and warrants that such person is duly and validly authorized to do so on behalf of the entity it purports to
bind and if such party is a partnership, corporation or trustee, that such partnership, corporation or trustee
has full right and authority to enter into this Agreement and perform all of its obligations hereunder.
9.17 Joint and Several Liability. University District and Vast Oak agree to and shall
be jointly and severally liable for all obligations of Developer under this Agreement.
Signatures on Next Page
14
IN WITNESS WHEREOF, City and Developer have executed this Agreement as of the
Effective Date.
Dated:
"DEVELOPER"
Keiser 42 LLC
A California Limited Liability Company
By: ____________________________
Name: Stephen Miller
Title: Executive Vice President
"CITY"
CITY OF ROHNERT PARK, a California
municipal corporation
Dated: By:
City Manager
Per Resolution No. 2020-____ adopted by the Rohnert Park
City Council at its meeting of September 22, 2020.
ATTEST:
City Clerk
APPROVED AS TO FORM:
City Attorney
15
ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
STATE OF CALIFORNIA )
) ss.
COUNTY OF SONOMA )
On __________________ before me, _______________________________________,
(here insert name and title of the officer)
personally appeared _______________________________, who proved to me on the basis of satisfactory
evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged
to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their
signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and official seal.
Signature ________________________________
(Seal)
16
ACKNOWLEDGMENT
A notary public or other officer completing this
certifi cate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
STATE OF CALIFORNIA )
) ss.
COUNTY OF CONTRA COSTA )
On __________________ before me, _______________________________________,
(here insert name and title of the officer)
personally appeared _______________________________, who proved to me on the basis of satisfactory
evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged
to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their
signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s ) acted,
executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and official seal.
Signature ________________________________
(Seal)
17
ACKNOWLEDGMENT
A notary public or other officer completing this
certificate verifies only the identity of the individual
who signed the document to which this certificate is
attached, and not the truthfulness, accuracy, or
validity of that document.
STATE OF CALIFORNIA )
) ss.
COUNTY OF SONOMA )
On __________________ before me, _______________________________________,
(here insert name and title of the officer)
personally appeared _______________________________, who proved to me on the basis of satisfactory
evidence to be the person(s) whose name(s) is/are subscribed to the within instrument and acknowledged
to me that he/she/they executed the same in his/her/their authorized capacity(ies), and that by his/her/their
signature(s) on the instrument the person(s), or the entity upon behalf of which the person(s) acted,
executed the instrument.
I certify under PENALTY OF PERJURY under the laws of the State of California that the foregoing
paragraph is true and correct.
WITNESS my hand and official seal.
Signature ________________________________
(Seal)
19907.000
7/2/2020
Page 1 of 2
P:\19907\SRV\Mapping\Desc\DESC BRISTOL EXCEPT ROW DEDICATION.doc
EXHIBIT A
LEGAL DESCRIPTION
FOR APN/PARCEL ID(S): 045-253-009-000, 045-253-010-000, 045-253-011-000 AND 045-253-012-000
THE LAND REFERRED TO HEREIN BELOW IS SITUATED IN THE CITY OF ROHNERT PARK,
COUNTY OF SONOMA, STATE OF CALIFORNIA AND IS DESCRIBED AS FOLLOWS:
PARCEL ONE (APN: 145-253-010-000):
ALL THAT PORTION OF THE SOUTHWEST QUARTER OF SECTION 19, TOWNSHIP 6 NORTH,
RANGE 7, WEST, M.D.B. & M., AND BEING THAT PART OF THE "RISK TRACT", DESCRIBED IN
THAT DEED TO DAVID RISK AND OTHERS, DATED APRIL 20, 1899, AND RECORDED MAY 5, 1899
IN BOOK 184 OF DEEDS, PAGE 474, MORE PARTICULARLY DESCRIBED AS FOLLOWS:
COMMENCING AT THE SOUTHWEST CORNER OF THE LAND DESCRIBED IN THE DEED
RECORDED IN BOOK 184 OF DEEDS, PAGE 474, INDICATED BY A STAKE MARKED "RISK",
THENCE NORTH ALONG THE WEST LINE OF THE LAND SO DESCRIBED IN THE DEED TO DAVID
RISK RECORDED IN BOOK 184 OF DEEDS, PAGE 474, A DISTANCE OF 1247.40 FEET TO A POINT
IN THE CENTER OF A 40 FOOT ROAD (KEISER ROAD); THENCE ALONG THE CENTERLINE OF
SAID ROAD, NORTH 89° 16' EAST, 405.4 FEET TO THE TRUE POINT OF BEGINNING OF THIS
DESCRIPTION; THENCE SOUTH, A DISTANCE OF 333.21 FEET TO AN IRON PIPE; THENCE EAST A
DISTANCE OF 222.8575 FEET; THENCE NORTH A DISTANCE OF 336.06 FEET TO A POINT IN THE
CENTERLINE OF KEISER ROAD; THENCE SOUTH 89°16' WEST, 222.875 FEET TO THE POINT OF
BEGINNING.
PARCEL TWO (APN: 145-253-011-000):
ALL THAT PORTION OF THE SOUTHWEST QUARTER OF SECTION 19, TOWNSHIP 6 NORTH,
RANGE 7, WEST, M.D.B. & M., AND BEING THAT PART OF THE "RISK TRACT", DESCRIBED IN
THAT DEED TO DAVID RISK AND OTHERS, DATED APRIL 20, 1899, AND RECORDED MAY 5, 1899
IN BOOK 184 OF DEEDS, PAGE 474, MORE PARTICULARLY DESCRIBED AS FOLLOWS:
COMMENCING AT THE SOUTHWEST CORNER OF THE LAND DESCRIBED IN THE DEED
RECORDED IN BOOK 184 OF DEEDS, PAGE 474, INDICATED BY A STAKE MARKED "RISK",
THENCE NORTH ALONG THE WEST LINE OF THE LAND SO DESCRIBED IN THE DEED TO DAVID
RISK RECORDED IN BOOK 184 OF DEEDS, PAGE 474, A DISTANCE OF 1247.40 FEET TO A POINT
IN THE CENTER OF A 40 FOOT ROAD (KEISER ROAD); THENCE ALONG THE CENTERLINE OF
SAID ROAD, NORTH 89° 16' EAST, 628.275 FEET TO THE TRUE POINT OF BEGINNING OF THIS
DESCRIPTION; THENCE SOUTH, A DISTANCE OF 336.06 FEET; THENCE EAST A DISTANCE OF
222.8575 FEET; THENCE NORTH A DISTANCE OF 338.91 FEET TO A POINT IN THE CENTERLINE
OF KEISER ROAD; THENCE SOUTH 89° 16' WEST, 222.875 FEET TO THE POINT OF BEGINNING.
PARCEL THREE (APN: 145-253-012-000):
ALL THAT PORTION OF THE SOUTHWEST QUARTER OF SECTION 19, TOWNSHIP 6 NORTH,
RANGE 7, WEST, M.D.B. & M., AND BEING THAT PART OF THE "RISK TRACT", DESCRIBED IN
THAT DEED TO DAVID RISK AND OTHERS, DATED APRIL 20, 1899, AND RECORDED MAY 5, 1899
IN BOOK 184 OF DEEDS, PAGE 474, MORE PARTICULARLY DESCRIBED AS FOLLOWS:
COMMENCING AT THE SOUTHWEST CORNER OF THE LAND DESCRIBED IN THE DEED
RECORDED IN BOOK 184 OF DEEDS, PAGE 474, INDICATED BY A STAKE MARKED "RISK";
THENCE NORTH ALONG THE WEST LINE OF THE LAND SO DESCRIBED IN THE DEED TO DAVID
RISK RECORDED IN BOOK 184 OF DEEDS PAGE 474, A DISTANCE OF 1247.40 FEET TO A POINT IN
THE CENTER OF A 40 FOOT ROAD (KEISER ROAD); THENCE ALONG THE CENTERLINE OF SAID
ROAD, NORTH 89° 16' EAST, 851.150 FEET TO THE TRUE POINT OF BEGINNING OF THIS
DESCRIPTION; THENCE SOUTH, A DISTANCE OF 338.91 FEET; THENCE EAST A DISTANCE OF
222.8575 FEET; THENCE NORTH A DISTANCE OF 341.76 FEET TO A POINT IN THE CENTERLINE
OF KEISER ROAD; THENCE SOUTH 89° 16' WEST, 222.875 FEET TO THE POINT OF BEGINNING.
PARCEL FOUR (APN: 145-253-009-000):
ALL THAT PORTION OF THE SOUTHWEST QUARTER OF SECTION 19, TOWNSHIP 6 NORTH,
RANGE 7, WEST, M.D.B. & M., AND BEING THAT PART OF THE "RISK TRACT", DESCRIBED IN
THAT DEED TO DAVID RISK AND OTHERS, DATED APRIL 20, 1899, AND RECORDED MAY 5, 1899
IN BOOK 184 OF DEEDS, PAGE 474, MORE PARTICULARLY DESCRIBED AS FOLLOWS:
19907.000
7/2/2020
Page 2 of 2
P:\19907\SRV\Mapping\Desc\DESC BRISTOL EXCEPT ROW DEDICATION.doc
COMMENCING AT THE SOUTHWEST CORNER OF THE LAND DESCRIBED IN THE DEED
RECORDED IN BOOK 184 OF DEEDS, PAGE 474, INDICATED BY A STAKE MARKED "RISK";
THENCE NORTH ALONG THE WEST LINE OF THE LAND SO DESCRIBED IN THE DEED TO DAVID
RISK RECORDED IN BOOK 184 OF DEEDS, PAGE 474, A DISTANCE OF 1247.40 FEET TO A POINT
IN THE CENTER OF A 40 FOOT ROAD (KEISER ROAD); THENCE ALONG THE CENTERLINE OF
SAID ROAD, NORTH 89° 16' EAST, 1074.025 FEET TO THE TRUE POINT OF BEGINNING OF THIS
DESCRIPTION; THENCE SOUTH A DISTANCE OF 341.76 FEET; THENCE EAST, A DISTANCE OF
222.8575 FEET TO AN IRON PIPE; THENCE NORTH A DISTANCE OF 344.62 FEET TO A POINT IN
THE CENTERLINE OF KEISER ROAD; THENCE SOUTH 89° 16' WEST, 222.875 FEET TO THE POINT
OF BEGINNING.
EXCEPTING THEREFROM:
THE PORTION OF KEISER AVENUE DEDICATED TO THE CITY OF ROHNERT PARK AS
DESCRIBED IN DOCUMENT NUMBER 2020-______, SONOMA COUNTY RECORDS
Exhibit B - Public Facilities and Water Capacity Charge Credit Calculations
Assumptions:
1. Bristol constucts 640 feet of roadway (Snyder to Model Home Driveway)
2. Work includes demo, earthwork, lime treat, base rock, curb, gutter and 1st lift AC, recycled water main extension from Snyder Lane and hydrants
Length 640 feet
Item No Item Quantity Unit Unit Cost Item Cost
20% Contingency
25% Management
Total Cost per
CL Foot
1 Mobilization 10.00 %300.54$ 30.05$ 13.52$ 43.58$
2 Clear & Grub 32.00 SF 0.27$ 8.64$ 3.89$ 12.53$
3 Pavement Removal 24.00 SF 2.80$ 67.20$ 30.24$ 97.44$
4 Earthwork (curb to curb)2.51 CY 14.91$ 37.42$ 16.84$ 54.26$
5 Lime Treat (curb to curb)3.78 SY 1.16$ 4.38$ 1.97$ 6.36$
6 Pavement (3" AC/13" AB)31.00 SF 5.90$ 182.90$ 82.31$ 265.21$
7 Pavement (6"AC/18" AB)0.00 SF 6.19$ -$ -$ -$
8 2" Overlay 0.00 SF 2.39$ -$ -$ -$
479.37$
9 Mobilization 10 %76.85 7.69$ 3.46$ 11.14$
10 Curb and Gutter 2 LF 26.5 53.00$ 23.85$ 76.85$
11 Median Curb 0 LF 6.14 -$ -$ -$
12 PCC Sidewalk (6' each side)0 SF 6.14 -$ -$ -$
13 Streetlighting 0 EA 5000 -$ -$ -$
14 Landscaping (5' with 6" curb)0 SF 6.5 -$ -$ -$
15 Underground Utilities 0 LF 127.42 -$ -$ -$
87.99$
Total Cost per CL Foot 567.37$
PF Credit for 640 feet of Surface Improvements (Rounded)363,115.00$
Item No Item Quantity Unit Unit Cost Item Cost
1 8" Recycled Water Main 675 LF 146.50$ 98,887.50$
2 Tie in at Snyder 1 EA 15,350.00$ 15,350.00$
PF Credit for Reycled Water Main 114,237.50$
Item No Item Quantity Unit Unit Cost Item Cost
1 Fire Hydrants 2 EA $12,000 $24,000
Water Capacity Charge Credit $24,000
Public Facility Fee Credit
Water Capacity Charge Credit
Surface Costs
Median and Frontage Costs
Subtotal Surface Costs per CL Foot
Subtotal Median and Frontage Costs per CL Foot
Recycled Water Main (included in PF Sewer Component with RP Reuse System)